Loading...
HomeMy WebLinkAboutRes 15-13 Approving an Agreement with Childs Play for Playground Equipment at Westlake AcademyTOWN OF WESTLAKE RESOLUTION NO. 15-13 A RESOLUTION OF THE TOWN COUNCIL OF THE TOWN OF WESTLAKE, TEXAS, APPROVING THE AGREEMENT FOR $118,612.00 WITH CHILD'S PLAY, INC., TO INSTALL NEW PLAYGROUND EQUIPMENT AT THE WESTLAKE ACADEMY CAMPUS AND AUTHORIZE TOWN MANAGER TO MAKE FUNDING CHANGES NOT TO EXCEED $25,000.00 ON THIS PROJECT. WHEREAS, the Town of Westlake owns and operates the Westlake Academy and provides facilities for Town and Academy use; and WHEREAS, the new playground equipment will develop eye hand coordination, enhance decision making skills, and offer opportunities for physical, social, & psychological growth of the students in grade K -G5; and WHEREAS, approving the agreement with Child's Play, Inc., to install new playground equipment at the Westlake Academy Campus; and WHEREAS, the Council finds that the passage of this Resolution is in the best interest of the citizens of the Town of Westlake, Texas. NOW, THEREFORE, BE IT RESOLVED BY THE TOWN COUNCIL OF THE TOWN OF WESTLAKE, TEXAS: SECTION 1: That, all matters and recitals stated hereinabove are found to be true and correct and are incorporated herein by reference as it copied in their entirety. SECTION 2: That, the Town Council of the Town of Westlake, Texas, hereby approves the agreement with Child's Play Inc. attached to this resolution as Exhibit "A'; and authorizes the Town Manager to execute the contract on behalf of the Town of Westlake. SECTION 3: That the Town of Westlake Town Council hereby authorizes the Town Manager to approve change orders to this agreement up to $25,000.00 in the aggregate, on behalf of the Town of Westlake. SECTION 4: If any portion of this Resolution shall, for any reason, be declared invalid by any court of competent jurisdiction, such invalidity shall not affect the remaining provisions hereof and the Council hereby determines that it would have adopted this Resolution without the invalid provision. Resolution 15-13 Page 1 of 2 SECTION 5: That this Resolution shall become effective from and after its date of passage. PASSED AND APPROVED ON THIS 15TH DAY OF JUNE 2015. M ��f ' KeIWEdwar s, Town Secretary m Laura Wheat, Mayor • - Fwn Manager i `a Resolution 15-13 Page 2 of 2 AGREEMENT BETWEEN TOWN AND CONTRACTOR THIS AGREEMENT is dated as of the 15th day of June in the year 2015, by and between the Town of Westlake, Texas (hereinafter called OWNER) and Child's Play, Inc. (hereinafter called CONTRACTOR). OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: Article 1. WORK. CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: The furnishing of all labor, shipping, materials, equipment, and incidentals for the Westlake Academy Expansion Phase I which include installing of all security systems listed in the scope. All manufacture and warranty information must be provided in three ring notebook and CD. Article 2. CONTRACT TIME. 3.1. CONTRACTOR agrees to commence work within five (5) days after the date of written notice to commence work, and to complete the work on which he has bid within eighty (80) working days as provided in the General Conditions. Article 3. CONTRACT PRICE. 4.1. OWNER shall pay CONTRACTOR for completion of the Work on a Unit Price Work Basis in accordance with the Contract Documents in current funds based on the measured quantities and the unit prices stated in the Proposal. Article 4. PAYMENT PROCEDURES. CONTRACTOR shall submit Applications for Payment on work completed during the previous month on the first day of the month. CONTRACTOR shall present only one Application for Payment each month. Applications for Payment will be processed by OWNER shall make payment to CONTRACTOR within thirty (30) days of the date of the invoice. Article 5. INTEREST. All moneys not paid when due shall bear interest at the maximum rate allowed by law at the place of the Project. Article 6. CONTRACTOR'S REPRESENTATIONS. In order to induce OWNER to enter into this Agreement, CONTRACTOR makes the following representations: 6.1 CONTRACTOR has familiarized itself with the nature and extent of the Contract Documents, Work, site, locality, and all local conditions and Laws and Regulations that in any manner may affect cost, progress, performance or furnishing of the Work. 6.2. CONTRACTOR binds itself to use such materials and so construct the work that it will remain in good repair and condition for and during the period of one (1) year from the date of the repair and to maintain said work in good repair and condition for said term of one (1) year. CONTRACTOR binds itself to repair or replace the furnishing in whole or in part at any time within said period, if, in the opinion of the owner, it be deemed necessary. Resolution 15-13 Page 1 of 3 6.3. To the fullest extent permitted by laws and Regulations, CONTRACTOR shall indemnify and hold harmless OWNER and ARCHITECT and their consultants, agents and employees from and against all claims, damages, losses and expenses, direct, indirect or consequential (including but not limited to fees and charges of engineers, architects, attorneys and other professionals and court and arbitration costs) arising out of or resulting from the performance of Work, provided that any such claim, damage, loss or expense (a) is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself) including the loss of use resulting there from and (b ) is caused in whole or in part by any negligent act or omission of CONTRACTOR, and Subcontractor, any person or organization directly or indirectly employed by any of them to perform or furnish any of the Work or anyone for whose acts any of them may be liable, regardless of whether or not it is caused in part by a party indemnified hereunder or arises by or is imposed by Laws and Regulations regardless of the negligence of any such party. 6.4. In any and all claims against OWNER or ARCHITECT or any of their consultants, agents or employees by any employee of CONTRACTOR, any Subcontractor, any person or organization directly or indirectly employed by any of them to perform or furnish any of the Work or anyone for whose acts any of them may be liable, the indemnification obligation under paragraph 6.3 shall not be limited in any way by any limitation on the amount or type of damages, compensation or benefits payable by or for CONTRACTOR or any such Subcontractor or other person or organization under workers' or workmen's compensation acts, disability benefit acts or other employee benefit acts. Article 7. Contract Documents The Contract Documents which comprise the entire agreement between OWNER and CONTRACTOR concerning the Work consists of the following: 7.1. Proposal 7.2. This Agreement 7.3. Performance Bond and Payment Bond 7.4. General Conditions There are no Contract Documents other than those listed above in this Article 7. Article 8. TERMINATION. OWNER may terminate contract if CONTRACTOR persistently fails to perform the work in accordance with the Contract Documents including, but not limited to, failure to supply sufficient skilled workers, or suitable materials or equipment, or otherwise violates in any substantial way any provisions of the Contract Documents. OWNER may, after giving CONTRACTOR seven (7) days written notice and to the extent permitted by Laws and Regulations, terminate the services of CONTRACTOR, exclude CONTRACTOR from the site and take possession of the Work. Article 9. MISCELLANEOUS. 10.1. No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound, and specifically but without limitation moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 10.2. In no event shall either OWNER or CONTRACTOR be liable to the other party hereto for special Resolution 15-13 Page 2 of 3 indirect, incidental, or consequential damages, including commercial loss, loss of use, or lost profits, even if either party has been advised of the possibility of such damages. OWNER and CONTRACTOR each binds itself, its partners, successors, assignees and legal representatives to the other party hereto, its partners, successors, assignees and legal representatives in respect of all covenants, agreements and obligations contained in the Contract Documents. IN WITNESS WHEREOF, OWNER and CONTRACTOR have signed Three (3) copies of the Agreement. Two counterparts each have been delivered to OWNER and CONTRACTOR. All portions of the Contract Documents have been signed or identified by OWNER and CONTRACTOR. This agreement will be effective on the 15th day of June, 2015. OWNER: CONTRACTO%R: 64 0�4SITown of Westlake, Texas By: -- By: Thomas E. Bry'(o "n Manager ATTEST: i , _.d ATI Kellydwards own Secretary Address for giving notices: 3 Village Circle, Suite 202 Westlake, Texas 76262 (If OWNER is a public body, attach resolution authorizing execution of Agreement. ) (if CONTRACTOR is a Corporation, attach evidence of authority to sign.) Resolution 15-13 Page 3of3 Li b ertx Mutual. Bond No. 019036073 RES 15-13 Document A312 TM -2010 Conforms with The American Institute of Architects AIA Document 312 CONTRACTOR: (Name, legal status and address) Child's Play, Inc. 10661 Shady Trail Dallas, TX 72550 OWNER: (Name, legal status and address) Town of Westlake 3 Village Circle Suite 202 Westlake, TX 76262 CONSTRUCTION CONTRACT Date: June 15, 2015 Amount: $ 118,612.00 SURETY: (Name, legal status and principal place of business) Liberty Mutual Insurance Company 175 Berkeley Street Boston, MA 02116 Mailing Address for Notices Liberty Mutual Insurance Company Attention: Surety Claims Department 1001 4th Avenue, Suite 1700 Seattle, WA 98154 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. One Hundred Eighteen Thousand Six Hundred Twelve Dollars and 00/100 Description: (Name and location) New Playground Equipment at the Westlake Academy Campus BOND Date: June 25, 2015 (Not earlier than Construction Contract Date) Amount: $ $118,612.00 One Hundred Eighteen Thousand Six Hundred Twelve Dollars and 00/100 Modifications to this Bond: ] None F] See Section 16 CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Child's Play, Inc. Signature: Name and Title: Kat IA. Robertson, V.P. SURETY Company: Liberty N Signature: Name and Title: Attorney -in -Fact (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY —Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Wells Fargo Insurance Services, Inc. (Architect, Engineer orotherparty.) Four Gateway Center, 444 Liberty Avenue, Suite 1500 Pittsburgh, PA 15222 412-765-3510 S-18521AS 8/10 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, Mthin five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. S-1852/AS 8/10 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perforin and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. S-1852/AS 8/10 § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of addedparties, other than those appearing on the coverpage.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: Signature: Signature: _ Name and Title: Name and Title: Address Address S-1852/AS 8110 (Corporate Seal) Liberty Mutt 1: 10� Payment Bond CONTRACTOR: (Name, legal status and address) Child's Play, Inc. 10661 Shady Trail Dallas, TX 72550 OWNER: (Name, legal status and address) Town of Westlake 3 Village Circle Suite 202 Westlake, TX 76262 Bond No. 019036073 Conforms with The American Institute of Architects AIA Document 312 SURETY: (Name, legal status and principal place of business) Liberty Mutual Insurance Company 175 Berkeley Street Boston, MA 02116 Mailing Address for Notices Liberty Mutual Insurance Company Attention: Surety Claims Department 1001 4th Avenue, Suite 1700 Seattle, WA 98154 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONSTRUCTION CONTRACT Date: June 15, 2015 Amount: $ 118,612.00 One Hundred Eighteen Thousand Six Hundred Twelve Dollars and 00/100 Description: (Name and location) New Playground Equipment at the Westlake Academy Campus BOND Date: June 25, 2015 (Not earlier than Construction Contract Date) Amount: $ 118,612.00 One Hundred Eighteen Thousand Six Hundred Twelve Dollars and 00/100 Modifications to this Bond: © None R See Section 18 CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Child's Play, Inc. Signature: f Name and Title: Kath . Robertson, V.P. SURETY Company: (Corporate Seal) P_Msu,� Liberty Mutual Insurance Company ��°�coBPO�ry�F f ) 1912 Signature: Name Karen Bachy t� and Title: Attorney -in -Fact (Any additional signatures appear on the last page of this Payment Bond.) (FOR INFORMATION ONLY —Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Wells Fargo Insurance Services, Inc. (Architect, Engineer orotherparty.) Four Gateway Center, 444 Liberty Avenue, Suite 1500 Pittsburgh, PA 15222 412-765-3510 S-2149/AS 8/10 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment famished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. S-2149/AS 8/10 § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase ordeis and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were famished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly famish a copy of this Bond or shall permit a copy to be made. 16 Definitions 16.1 Claim. A written statement by the CIaimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was famished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment famished; .5 the date on which the Claimant last performed labor or last famished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were famished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. S-21491AS 8110 § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of addedparties, other than those appearing on the coverpage.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: Signature: Signature: _ Name and Title: Name and Title: Address Address S-2149/AS 8/10 (Corporate Seal) This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except In the manner and to the extent herein stated. Not valid for mortgage, note, loan, tetter of credit, bank deposit, currency rate, interest rate or residual value guarantees. To confirm the validity of this Power of Attorney call 610.832.8240 between 9:00 am and 4:30 pm EST on any business day. American Fire and Casualty Company Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company 1:101>t1:4i�01asT4W0iSol 1� T� KNOWN ALL PERSONS BY THESE PRESENTS: That American Fire & Casualty Company and The Ohio Casualty Insurance Company are corporations duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duty organized under the laws of the State of Indiana (herein collectively called the 'Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Karen Bach of the city of Pittsburg , state of PA its true and lawful attorney-in-fact, with full power and authority hereby conferred to sign, execute and acknowledge the following surety bond: Principal Name: Child's Play, Inc. Obligee Name: Town of Westlake Surety Bond Number: 019036073 Bond Amount: See Bond Form IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 18d, day of November, 2013. BIND CASG IL%"SUR JI�Tf INSr/ILy%NSUJ{Ay American Fire and Casualty Company �oonroRyT�s�� aJ �oaPogyT'y� ey �oOPrORyrF y��.o�`�ao,�l �F The Ohio Casualty Insurance Company 2 a o p o Liberty Mutual Insurance Company 1906 0 1912 = 1919 3 N 1991 a Wes mencan Insurance Company �fYy hAMP��-L Oma) 9S'rACNU`'�T= yd �NAM� !� � �VDIAN Y 1 By: * * * * David :'Carey, Assistant Secretary STATE OF PENNSYLVANIA COUNTY OF MONTGOMERY On this 181^ day of November. 2013, before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of American Fire and Casualty Company, Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first above written. 9I PggT F< COMMONWEALTH OF PENNSYLVANIA Notarial Seat — OF Teresa Pastella, Notary Public By: Plymouth Twp., Montgomery County Teresa Pastella, otary Public My Commission Expires March 28, 2017 qRyt Member Pennsylvania Association of Notaries This Power of Attome 'made and executed pursuant to and by authority of the following By-laws and Authorizations of American Fire and Casualty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV — OFFICERS — Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attomeys4n-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recogn¢ances and other surety obligations. Such attorneys -In -fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney- in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE Xllt — Execution of Contracts — SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attomeys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys - in -fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognrzances and other surety obligations. Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. 1, Gregory W. Davenport, the undersigned, Assistant Secretary, of American Fire and Casualty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, trine and correct copy of the Power of Attomey executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 25th day of June 2015_. IND CAS tNSU ��Y INSf/ NWSW? 2Qti=ootwoRyr�o9�� �v2` �o��r,^ `ey��oo�O,�ylo2c„n �Tyro By: 19063 0 1912 i 1919 N 1991 a Cr e` a 3 C�L'� civ HAMP` �a j 9SSACtN`'" Gregory W. Davenport, Assistant Secretary